Standard Website and Marketing Plans Terms & Conditions
Thank You for choosing Global Presence Enterprises, LLC (GPM, GPE, GPS, Global Presence, Global Presence Marketing, Global Presence Solutions). All agreements are made solely between the Client, “You” (the party to whom the Company provides services), and “Global Presence” at the moment of purchase. By making payment, clients ensure they have downloaded their records and understand, maintain, and access terms and agreements with the link provided in written proposals or invoices.
2. Project Definition
These Business Terms should be read in conjunction with the Project Definition sent to You simultaneously (“Project Definition”), which incorporates these Terms of Business. The Project Definition sets out, amongst other things, the services Global Presence will provide to You (“Works”) and the fees which will be charged (“Fees”). Additional defined terms are set out in the Project Definition. Global Presence aims to offer a friendly and efficient service and exercise reasonable skill, care, and diligence in carrying out the Works.
These Terms of Business come into force with immediate effect upon Your first instructions or order, and these Terms of Business will apply to any current and future instructions or commission that You are kind enough to give Global Presence and to any specific Works referred to in the current or a future Project Definition.
These Business Terms and the Project Definition constitute the agreement between Global Presence and You regarding the Works. Any additional work not specified in the Project Definition must be authorized by a written change order signed by You and Global Presence and may result in changes to Fees and Disbursements.
3. Your Brief
You, as Global Presence client, represent, undertake and warrant to Global Presence that, to the best of Your knowledge: (i) any instructions are given and materials supplied by You will be accurate and complete and will not cause Global Presence to infringe the rights (including intellectual property rights) of any third party or the laws or regulations (including data protection legislation) of any country and (ii) You have complied and will comply with the Minimum Client Requirements set out in the Project Definition.
Global Presence and You agree to work together to complete the Works promptly. Global Presence agrees to work expeditiously to complete the Works in line with the Timeframe agreed in the Project Proposal emailed to you; however, this Timeframe is dependent on Global Presence being provided with Your continued cooperation to approve Works at various stages. Global Presence cannot be held responsible for any loss incurred. You (or any third party instructed by You) have not provided clear and complete instructions within any given time limit and with sufficient notice.
If You request changes to the Works Global Presence, reserve the right to revise the Project Definition. If the Works are shortened, delayed, canceled, or terminated early by You, the final invoice will include the balance of the Fees for providing the Works plus any reasonable costs and disbursements incurred by Global Presence due to Your acts or omissions. For example, You shall be liable for the costs and disbursements incurred by Global Presence for prebooked fieldwork, which is delayed, not used, or not fully used.
Global Presence recommends that You retain copies and backups of all materials, data, or information provided to and from Global Presence.
Global Presence reserves the right to assign subcontractors to this project to ensure the right fit for the job and timely completion. Global Presence shall be the primary obligor concerning such sub-contractors.
Global Presence is only responsible for the quality of the service provided by subcontractors if those subcontractors have been selected and paid for directly by Global Presence. If You designate a specific sub-contractor, then Global Presence shall not be responsible for that sub-contractor's work's accuracy, completeness, or quality.
5. Fees and Disbursements
Global Presence Fees are exclusive of tax which must, therefore, be added at the current rate if you're not tax-exempt. This will be indicated on invoices. Global Presence Fees are also exclusive of disbursements (including travel), therefore charged in addition. Disbursements include payments made or incurred on Your behalf and miscellaneous office expenses such as printing, traveling, and out-of-pocket expenses. Mileage will be charged in line with IRS guidelines. The client must pre-approve all expenses within the agreed-upon the project's actual and projected budget expenses.
Payment of Fees for Works shall be on delivery of the Works. Any Works provided over more than one calendar month will be subject to an invoice at the start of each calendar month, with the final invoice raised on the delivery of the last works. All invoices shall be due on the invoice date and shall be subject to payment on that date.
If You dispute, or deem any invoice, contract, or agreement incorrect or inaccurate, Global Presence must be notified, in writing, within 48 hours of receipt. Failure to do so renders any future claim inadmissible.
For Global Presence to remain in business, payments must be made promptly. A ten-dollar additional fee will be incurred if payment is not received within ten (10) days of the due date. If an amount remains delinquent thirty (30) days after its due date, an additional five percent (5%) interest will be added for each month of delinquency from the date of the invoice. Global Presence reserves the right to suspend work without notice until Final Payment is made. Where debt collection or proceedings prove necessary, You agree to pay all fees and costs incurred by that process.
6. Confidentiality and Intellectual Property
All information You provide to Global Presence will be regarded as confidential to the extent that it is not in the public domain. Still, You should advise Global Presence if any information is particularly sensitive. Global Presence will not divulge any confidential information obtained from You other than your instructions.
You unconditionally guarantee that any elements of text, graphics, photos, designs, trademarks, or other artwork (including all associated intellectual property) furnished by You (or on Your behalf) to Global Presence for inclusion in the Works are owned by You or that You have permission from the rightful owner to use each of these elements, and will hold harmless, indemnify, and defend Global Presence and its subcontractors from any claim or suit arising from the use of such elements furnished by You.
In the first instance, Global Presence owns intellectual property rights (including but not limited to copyright and database rights) in all Works. All intellectual property rights owned by Global Presence in finished, approved Works created specifically for You will be assigned to You automatically on receipt by Global Presence of the Final Payment of Fees in cleared funds. All Intellectual property rights in third-party materials are owned by those third parties and will be licensed to You on the terms set out in the Project Definition.
Global Presence and its subcontractors retain the right to display Works, graphics, and other design elements as examples of their work in their respective portfolios (including online).
Either party may terminate this engagement upon one month's notice unless in an agreement as to the invoice or quote states. The notice must be provided in writing. Global Presence will use its reasonable endeavors to complete any Works in progress, and Global Presence will remain entitled to payment for completing those Works.
Either party may terminate this engagement immediately for a material breach by the other which is incapable of remedy or, if capable of remedy, is not remedied within 45 days of notification being given to the defaulting party.
For a good reason and upon reasonable notice, Global Presence reserves the right to terminate Global Presence engagement without further liability on Global Presence. This will be confirmed to You in writing if requested. “Good reasons” include if You: do not give Global Presence instructions within a reasonable period; do not pay promptly any request for money on account, or do not pay a bill within the due period.
8. Warranties and Liability
All conclusions, recommendations, forecasts, reports, letters, or other communications, whether oral or written, provided by Global Presence (together, the “Recommendations”) are made in good faith and based on information available to Global Presence at the time, whether from You or information in the public domain and the validity of such Recommendations will depend, amongst other factors, on Your effective cooperation and the quality of the information made available by You. No warranty or representation, express or implied, is given as to the Recommendations provided by Global Presence. You shall be responsible for properly adapting such Recommendations to your circumstances.
All Recommendations given by Global Presence are for Your use only and are not to be disclosed or reproduced to third parties without the prior written consent of Global Presence.
Global Presence shall not be liable for any consequential or indirect loss suffered by You, whether such loss arises from a breach of contract or tort or in any other way (including losses arising indirectly or consequentially from Global Presence negligence). Compensation for any direct losses arising under this agreement shall be limited to the value of the current Project Definition.
You and Global Presence acknowledge that the Fees payable under these Terms of Business have been determined based on these limitations of liability and reflect the division of risks set out in these Terms of Business and that, accordingly, the division of risk is agreed by the parties to be fair and reasonable in the circumstances.
If any provision of this agreement shall be unlawful, void, or unenforceable for any reason. That provision shall be deemed severable from this agreement and shall not affect the validity and enforceability of any remaining provisions.
Global Presence does not provide in-house counsel services per se. When you contract with Global Presence, you are agreeing to Global Presence acting as an agent on your behalf and granting Global Presence the right to bind you contractually with a third-party (“Legal Third-Party”) who will provide the services of an in-house counsel and/or consultant. In this arrangement, Global Presence’s Standard Website and Marketing Plans Terms & Conditions will be terms that govern your relationship with the Legal Third-Party.
The services are provided by a Legal Third-Party who is registered or licensed within their place of residence and/or has the appropriate degrees from a recognized university program. The Legal Third-Party may not be licensed/registered in your town, city, state, province, region, or even in your country and therefore cannot be held liable regarding the services provided nor provide warranty that the services adhere to local rules and regulations. You understand that the services are in-house counsel and/or consultation services and not legal services and accept the services as is. You will hold harmless Global Presence and the Legal Third-Party for the services provided as part of the agreement when accepting these services.
9. Hourly Rates
An hourly package for the website that requires infrequent updates will suit client needs: $1.25 per minute/10-minute minimum charge.
Suppose the website requires more frequent updates, we recommend the purchase of a maintenance package/plan. Our site maintenance package includes the following:
Priority service, i.e., shorter turnaround
Updating, correcting, or creating new HTML web pages as requested.
Image scanning, image optimization, and image placement on websites.
Common Maintenance Task Include, but are not limited to:
Addition of new content, modification of existing content, and deletion of old material.
Website design upgrades or modifications.
Addition of new website features.
Adding new products.
Adding new extensions.
View current maintenance rates here: gp.marketing/plans
10. Maintenance Roll Over Hours
Global Presence does not roll over minutes/hours that are not used in the client's maintenance package.
11. Data Protection
Details of the individual to whom these Terms of Business are sent, together (where relevant) with details of other key individuals within Your organization supplied to Global Presence from time to time, will be entered onto the Global Presence client database. Global Presence will use these details primarily to provide You with the Works. In addition, Global Presence may use these details to contact You by post, telephone, e-mail, or fax for marketing purposes or to do searches with credit reference agencies. Global Presence may also disclose these details to any agents, associates, advisors, or contractors that we agree Global Presence should work with on Your behalf.
It is Your responsibility to ensure that the communication of any sensitive or personal data by You or Your agents to Global Presence does not breach the rights of any data subjects and that the use of such data by Global Presence according to the Project Definition does not breach any data protection regulations or legislation. You hereby indemnify Global Presence in this respect.
12. Electronic Communications
During this matter, we may wish to communicate electronically with one another. Electronic information transmission cannot be guaranteed to be secure or error-free, as it will be transmitted over a public network. Such information could be intercepted, corrupted, lost, destroyed, arrive late or incomplete, or otherwise be adversely affected or unsafe for use.
We agree to use reasonable procedures to check for the most recently known viruses before electronically sending and receiving information. Still, we recognize that such procedures cannot guarantee that transmissions will be virus-free. We shall each be responsible for protecting our interests in electronic communications. Neither of us shall be liable to the other on any basis, whether in contract, tort (including negligence), or otherwise, in respect of any damage or loss arising from or in connection with the electronic communication of information between us.
13. Content Guidelines
These types of sites are not allowed on Global Presence:
Adult: involving nudity in a sexual context, exposed genitalia, or adult themes
Copyrighted Content: music, movies, or games that you do not own the rights to
Hate Speech: content that promotes violence or incites hatred against certain individuals or groups, such as race, religion, ethnicity, gender, or sexual orientation. The foregoing examples are not meant to constitute an exhaustive list of individuals or groups that may be the target of hate speech.
Spam/SEO: a site whose sole purpose is to gain Google ranking, Facebook "likes," etc
Phishing: a site meant to trick users into providing their username and password
Illegal Content: content that may be illegal in the United States or under the laws of other countries
Scams: get rich quick, pyramid/MLM, or other dubious schemes
Excessive Advertising: placing excessive advertising on your site, including more than three ad units per page
File Hosting: including sites that are not created with the Global Presence editor
Injurious Experience: sites using the "Custom HTML" element that provide horrible user experiences, such as extreme flashing banners, excessive animated movement, or content that could provoke seizures in unsuspecting visitors
Illegal/Inappropriate Products: sites that offer or sell items that are illegal, weapons, counterfeit, stolen, fraudulent, infringing, violate rights of privacy/publicity, offensive, pornographic, or manufactured/intended to be weapons
This list is a quick reference and is not meant to be complete. For more specific information, please read the Terms carefully on this page.
14. Description of Web Services
Our web-based Service allows users who register for an account (each an "Account Holder") to create and update an online website. Once registered, each Account Holder receives their Website and may post "Content" (defined in Section 8). Any new features on the Service, including the release of new Global Presence tools and resources, shall be subject to these Terms.
To use the Service, you must have access to the Internet, either directly or through devices that access web-based content, and you must pay any fees associated with Internet access. In addition, you must provide all equipment necessary to make such a connection to the Internet, including a web-enabled computer.
The Service may include certain communications, such as service announcements, administrative messages, and the Global Presence Newsletter. These communications are considered part of Global Presence membership.
You may not access the Website by any means other than through the user interfaces or control panel we provide you. Our websites and extensions are rented on a month-to-month basis, 12-month lease, or 24-month lease agreements with an option to purchase. Unless stated in our proposals and invoice "Ownership Plan," all of our BIZ STARTER, BIZ PLUS, BIZ PRO, BIZ PREMIUM are rental or lease agreements by default.
Websites and extension buyout prices are typical $5,000.00 to $10,000.00, depending on the number of extensions and features we have added to your site that surpassed the monthly subscription fee. To transfer only the core files to another server is $200.00.
To register as an Account Holder, you must provide us with a valid email address and other personal information ("Registration Data"). You will choose a password and account designation for your websites during registration and obtain a Global Presence ID. You are responsible for maintaining the confidentiality of the password and account and for all activities that occur under your account. In consideration of the use of the Service, you agree to maintain and update true, accurate, current, and complete Registration Data. If you provide any information that is untrue, inaccurate, not current, or incomplete, or if Global Presence has reasonable grounds to suspect that such information is untrue, inaccurate, not current, or incomplete, we may suspend or terminate your account and refuse all current or future use of the Service or any portion thereof. In addition to the restrictions on selling outlined in Section 9 below, individuals under 13 are prohibited from creating or using accounts through Global Presence.com. However, students under 13 may use Global Presence through special student accounts created by their teachers through gp.marketing/education, provided the teacher has obtained signed parental consent from the student's parents.
16. Privacy Notice
Our Privacy Notice (available at https://gp.marketing/privacy), which is part of these Terms, describes how we collect, protect, and use your Registration Data and certain other information about you. We encourage you to read the Privacy Notice and use its information to help you make informed decisions.
17. Website account and security
You are responsible for maintaining your account and website's security for all activities that occur or actions taken under the account or in connection with the website. You agree to immediately notify us in writing of any unauthorized uses of the account or any other security breaches. We will not be liable for any loss or damage from your failure to comply with this security obligation. You acknowledge and agree that under no circumstances will Global Presence or any of its affiliates, subsidiaries, officers, directors, or employees be liable, in any way, for any of your acts or omissions or those of any third party, including damages of any kind incurred as a result of such acts or omissions.
18. Proprietary Rights
Global Presence owns the Site and Service. The Site and Service use and display content, features, and functionality, including but not limited to proprietary software, inventions, copyrights, trademarks, trade dress, service marks, logos, slogans, and taglines, owned by Global Presence or other unaffiliated third parties, that are protected by the U.S. and international copyright, trademark, patent, trade secret and/or other intellectual property or proprietary rights laws. No portion of the Site or Service may be copied, reproduced, displayed, transmitted, or otherwise used for any purpose without the prior written permission of Global Presence or the respective third-party intellectual property owner or as otherwise specifically provided herein. We reserve all rights not expressly granted in these Terms.
The Service, all confidential and proprietary software used in connection with the Service, Materials (as defined below), content contained in sponsor advertisements or the information presented to you through the Service or by advertisers, and all other materials and services provided by or through Global Presence are protected by copyright, trademark, trade secret, or other intellectual property laws. You are solely responsible for ensuring that your use of such Materials, including any “professional photos” or “free photos” made available through the Service, is done solely by all relevant laws and any terms or conditions applicable to such Materials. In no event shall Global Presence be liable to you or any third party for your use of Materials in violation of the law or any terms or conditions applicable to such Materials.
“Materials” means any software, text, software documentation, designs, "look and feel," layout, photographs, graphics, audio, video, messages, interactive and instant messaging, design and functions, files, documents, images, or other materials, whether publicly posted or privately transmitted, as well as all derivative works thereof, in each case, made available by or through Global Presence or the Service.
You may use the Materials to the extent, and only to the extent, necessary to access and use the Service by these Terms and, in the case of Materials owned by third parties made available to you by or through Global Presence or the Service, any third-party terms or conditions applicable to such Materials. This permission does not permit you to store, copy, reproduce, republish, modify, upload, post, translate, scrape, rent, lease, loan, sell, distribute, transfer, transmit, display, decompile, reverse engineer, reverse assemble, decipher (or otherwise attempt to discover any programming code or any source code used in or with the Materials), or otherwise distribute in any way the Materials other than as specifically permitted in these Terms. You may not sell, assign, sublicense, grant a security interest in or otherwise attempt to transfer any right in the Service or Materials, create derivative works based on or in any manner commercially exploit the Service or Materials, in whole or in part, other than as expressly permitted in these Terms. Any use of the Service or Materials for any purpose other than as specifically permitted herein and in any relevant third-party terms of service is expressly prohibited. We reserve all rights not expressly granted in these Terms.
All trademarks, service marks, logos, slogans, and taglines (individually and collectively, “Mark” or “Marks”) are the property of Global Presence or their respective owners. Except as otherwise specifically provided herein, no license or right to use any Mark is granted to you without the express written permission of Global Presence or the respective third-party Mark owner.
“Professional Photos”- By purchasing and/or using any “professional photos” available through the Service, you agree that: (i) you will use such “professional photos” on your Global Presence site only, for display solely in digital form; (ii) you will not sell, modify, re-use, re-sell, distribute, display, reproduce, or make any other use of such “professional photos”; (iii) where a “professional photo” features an individual and is used in connection with a sensitive, unflattering or controversial subject, you will include a statement that the image is used for illustrative purposes only and that the individual featured is a model; and (iv) you will not activate the “right-click” function in any “professional photo,” remove any metadata in any “professional photo,” or reverse engineer, decompile, or disassemble your site to enable the download or use of any “professional photo” on a standalone basis. In addition, you may not use any “professional photo”: (i) on a standalone basis with no other content; (ii) for pornographic, defamatory, or other unlawful purposes; (iii) to create or enable the creation of printed products; (iv) in physical or digital retail products, such as e-cards, calendars, posters, or screensavers; (v) to suggest or imply endorsement, sponsorship, or affiliation by or with any of the subject matter contained within the “professional photo;” (vi) to enable file-sharing of the image file; or (vii) in logos, trademarks, service marks or any other branding or identifiers.
19. Your rights in your Content
Global Presence does not claim ownership of your Content (as defined below). Still, you give us your permission worldwide to host your Content on the Service and perform all acts necessary to host your Content on the Service (such as making copies, reformatting, and distributing your Content). In other words, you grant our subsidiaries and us, affiliates, and successors a worldwide, non-exclusive, royalty-free, fully-paid, transferable, irrevocable, perpetual, and sub-licensable right to use, reproduce, modify, adapt, publish, prepare derivative works of, distribute, publicly perform, and publicly display your Content throughout the world in any media.
We do not want to receive confidential or proprietary information from you through the Service or by email. Unless otherwise agreed in writing by an authorized Global Presence representative, any material, information, or idea you transmit to us by any means may be disseminated or used by us or our affiliates without compensation or liability to you for any purpose whatsoever, including, but not limited to, developing, manufacturing and marketing products. However, this provision does not apply to Content or personal information subject to our Privacy Notice.
20. Content and conduct rules and obligations
All information, data, text, software, music, sound, photographs, graphics, video, messages, goods, products, services, or other materials you post on a website via the Service ("Content") are the sole property of the person from which such Content originated. You are responsible for all content you upload, post, transmit, or otherwise make available via the Service. We do not control the Content you post via the Service. Your Content does not include non-personally identifiable buyer/seller transactions or behavioral data derived from the use of Global Presence’s eCommerce platform (collectively, “Platform Data”). Global Presence owns all Platform Data and uses it for Service operations, improvements, and analytics. You are also responsible for creating backup copies of your Content.
You may be exposed to offensive, indecent, or objectionable content by using the Service. Under no circumstances will we be liable for your Content or the content of any third party, including, but not limited to, any errors or omissions in your Content or for any loss or damage of any kind incurred as a result of the use of any Content posted, transmitted or otherwise made available via the Service. You acknowledge that we do not pre-screen Content but that we shall have the right (but not the obligation) to refuse, move, or delete any Content available via the Service. We shall also have the right to remove any Content that violates these Terms or is otherwise objectionable at our sole discretion. You must evaluate and bear all risks associated with using any Content. You may not rely on any Content created by us. You acknowledge and agree that we may preserve Content and may also disclose Content if required to do so by law or in the good faith belief that such preservation or disclosure is reasonably necessary to (a) comply with legal process; (b) enforce these Terms; (c) respond to claims that any Content violates the rights of third-parties; or (d) protect our rights, property, or personal safety and those of our users and the public.
The technical processing and transmission of the Service, including Content, may involve (a) transmissions over various networks; and (b) changes to conform and adapt to the technical requirements of connecting networks or devices.
You will not:
A. upload, post, transmit, or otherwise make available any Content that:
i. is unlawful, harmful, threatening, abusive, harassing, tortuous, defamatory, vulgar, obscene, libelous, invasive of another's privacy (up to, but not excluding any address, email, phone number, or any other contact information without the written consent of the owner of such information), hateful, or racially, ethnically or otherwise objectionable;
ii. you do not have a right to transmit under any law or contractual or fiduciary relationships (such as inside information, proprietary and confidential information learned or disclosed as part of employment relationships, or under nondisclosure agreements);
iii. infringes any patent, trademark, trade secret, copyright, rights of privacy or publicity, or other proprietary rights of any party (e.g., music, movies, images, e-books, or games you do not own the rights to);
iv. is unsolicited commercial email or "spam." This includes unethical marketing, advertising, or any other practice that is in any way connected with "spam," such as (i) sending a mass email to recipients who haven't requested an email from you or with a fake return address, (ii) promoting a site with inappropriate links, titles, descriptions, or (iii) promoting your site by posting multiple submissions in public forums that are identical;
v. contains software viruses, worms, Trojan horses, or any other computer code, files, or programs that interrupt, destroy, or limit the functionality of the Service, computer software or hardware, or telecommunications equipment or may impact the ability of any Global Presence user to access the Service;
vi. is intended to take advantage of a user such as "get rich quick," "get paid to surf," pyramid/multi-level marketing, or other dubious schemes; or
vii. is adult in nature, such as any nudity in a sexual context or any Content with adult themes or reveals exposed genitalia;
B. harm minors in any way;
C. "stalk," “bully,” or otherwise harass another;
D. impersonate any person or entity, including, but not limited to, a Global Presence employee, forum leader, guide or host, or falsely state or otherwise misrepresent your affiliation with a person or entity;
E. forge headers or otherwise manipulate identifiers to disguise the origin of any Content transmitted through the Service;
F. interfere with or disrupt the Service or servers or networks connected to the Service, or disobey any requirements, procedures, policies, or regulations of networks connected to the Service;
G. intentionally or unintentionally violates any applicable local, state, federal or foreign laws or regulations. You must comply with all applicable laws regarding the transmission of technical data exported from the United States or the country in which you reside. If you use the Site, the Service, or the Materials outside the United States of America, you are solely responsible for compliance with all applicable laws, including, without limitation, rules regarding acceptable online conduct, data privacy, and export and import regulations of other countries;
H. promote or provides instructional information about illegal activities, promotes physical harm or injury against any group or individual, or promotes any act of cruelty to animals. This may include, without limitation, providing instructions on how to assemble bombs, grenades, and other weapons or incendiary devices;
I. use the Service as a forwarding service to another website or to fraudulently manipulate Google or other SEO ranking or Facebook or other social networking or website “likes” and similar voting mechanisms;
J. solicit a third party’s passwords or personal identifying information for unlawful or phishing purposes;
K. exceed the scope of the Service that you have signed up for (e.g., by accessing and using the tools that you do not have a right to use, or deleting, adding to, or otherwise changing other user comments or content);
L. include more than three ad units per page or any advertising that greatly reduces the usability of the Site;
M. upload files for the sole purpose of having them hosted by us and for use outside of a website created using the Service (i.e., created with the Global Presence editor);
N. creates a website that provides an injurious user experience with custom programming. Examples include, but are not limited to, extreme flashing banners, excessive animated movement, or content that could provoke seizures in unsuspecting visitors;
O. use, under any circumstance, any open-source software subject to the GNU Affero General Public License v.3, or greater;
P. Abuse our customer support email, chat, or telephone services or agents; or
Q. Take any other action while using the Service detrimental to the Service or Global Presence’s reputation, as determined by Global Presence in its sole discretion.
We retain the right to terminate any account or user who has violated any of the above prohibitions.
9. Selling Through Global Presence
Some of our Services and Materials may offer you the opportunity to sell or purchase goods and services through sites hosted or designed by Global Presence (such as goods and services, “Commercial Products”). We are merely providing the platform for buyers and sellers to conduct transactions for these Commercial Products. To sell through Global Presence, you must be 18 years or older or at least the age of majority in your Country of Residence. You must provide your full legal name, current address, valid email address, and any other information requested by us. In a dispute regarding Account ownership, we reserve the right to request documentation to determine or confirm account ownership. Documentation may include but is not limited to a scanned copy of your business license, government-issued photo ID, the last four digits of the credit card on file, etc.
YOU WILL NOT offer or sell any Commercial Products that:
are illegal or potentially illegal, including those that are counterfeited, stolen, or fraudulent. Commercial Products sold using the Services must comply with all applicable laws, including Commercial Products, sold to individuals outside of the U.S.;
infringe or have the potential to infringe the intellectual property or privacy rights of another or that may be libelous, slanderous, or otherwise defamatory;
we determine, at our discretion, are inappropriate, offensive, pornographic, sexually explicit, or violent; or
are manufactured as, or primarily intended to be used as, weapons, including firearms, restricted devices, or ammunition. We reserve the right to determine, in our sole discretion, whether Commercial Products constitute “weapons” for purposes of these Terms; or
use images or names of any third party (including notable personalities or celebrities) when offering or selling Commercial Products without first obtaining that third party’s permission.
21. Limitations on Use of Personal Information
For purposes of this section, “Personal Information” means any information that identifies, relates to, describes, is reasonably capable of being associated with, or could reasonably be linked, directly or indirectly with a particular consumer or household that is processed by Global Presence in connection with the Service.
For purposes of this section, “process,” “sell,” and “business purpose(s)” have the meaning ascribed to them in the Florida Consumer Privacy Act. We may receive Personal Information to perform the Service on your behalf as described in these Terms. We agree that we will process such Personal Information on your behalf and will not (a) sell the Personal Information; (b) retain, use or disclose the Personal Information for any purpose other than providing to you the Service specified in these Terms [and other applicable terms and agreements between you and Global Presence]. As part of and for purposes of facilitating the Service, Global Presence may (a) de-identify or aggregate the Personal Information; and (b) process the Personal Information for operational purposes, including, without limitation, verifying or maintaining the quality and safety of the Service; improving, updating or enhancing the Service, either for you or for our customers generally; and complying with our legal obligations. You acknowledge and agree that the Personal Information that you disclose to Global Presence is provided to Global Presence for the parties’ business purposes.
You may agree to a one (1) month, six (6) month, twelve (12) month, or twenty-four (24) month contract agreement with Global Presence or whatever terms Global Presence is making available on their website or by personal custom proposals. Some of the features on the Service require payment of fees, as described for each Service on the Site (“Fees”). If you sign up for these features, you must pay all applicable fees. We reserve the right to change our prices and/or bundle certain parts of the Service together for pricing purposes and may do so at any time. You authorize us to make any reasonably necessary inquiries to validate your account and financial information. The client can downgrade and upgrade by choosing the service plan when downgrading or upgrading; all set-up fees and monthly maintenance fees apply.
All Fees are in USD and do not include any taxes, levies, duties, or similar governmental assessments of any nature, including, for example, value-added, sales, use, or withholding taxes, assessable by any jurisdiction (collectively, “Taxes”). It is your responsibility to determine what, if any, Taxes apply to the payments you make or receive. It is solely your responsibility to assess, collect, report, and remit the correct taxes to the appropriate authority. If you purchase any services that we offer for a Fee, you consent to Global Presence, or our third-party service providers, storing your payment card information. You authorize us to charge you (a) any Fees for Services you may purchase and (b) any applicable Taxes in connection with your use of the Services to the payment card you provide, and you will reimburse us for all costs associated with the collection of any overdue amounts, including any interest due for the same. If the payment card you provide expires and you do not provide new payment card information or cancel your account, you authorize us to continue billing you. You will remain responsible for any uncollected Fees.
AT THE END OF THE CONTRACT TERM, YOUR CONTRACT WILL AUTOMATICALLY RENEW FOR AN ADDITIONAL CONTRACT TERM OF THE SAME LENGTH UNTIL EXPLICITLY CANCELLED BY YOU WITHIN 30 DAYS OF THE DUE DATE, AND YOUR PREFERRED PAYMENT METHOD WILL BE CHARGED ACCORDINGLY. YOU MAY TURN OFF THE AUTO-RENEW FEATURE FOR YOUR CURRENT CONTRACT AT ANY TIME. YOU MAY SEND CANCELLATION 30 DAYS BEFORE YOUR NEXT DUE DATE REQUESTS BY CONTACTING US THROUGH HTTP://GP.MARKETING OR BY CALLING OUR HELP CENTER AT ANY TIME.
23. Cancellation; Service Changes
If you cancel the Service online at https://gp.marketing/cancel, your cancellation will take effect 30 days after, and any extra payments will be invoiced. After cancellation, you will no longer have access to your website, and we may delete all information on your website. We accept no liability for such deleted information or content.
As long as we continue to offer the Service, we will provide and seek to update, improve, and expand the Service. As a result, we allow you to access the Service as it may exist and be available on any given day and have no other obligations, except as expressly stated in these Terms. We may modify (e.g., change data storage or capacity limits), replace, refuse access to, suspend or discontinue the Service, partially or entirely, or change and modify prices for all or part of the Services we offer at our sole discretion. All of these changes are effective upon their posting on our site or by direct communication to you unless otherwise noted. We further reserve the right to withhold, remove and or discard any Content available as part of your account, with or without notice if deemed by us, in our sole discretion, to be contrary to these Terms. To avoid doubt, we have no obligation to store, maintain, or provide you a copy of any Content that you or others provide when using the Service. We also reserve the right to limit or cease phone or chat support if you consume a disproportionate amount of such customer services or otherwise negatively affect our ability to support other customers (as determined at our sole discretion).
24. Money-Back Guarantee
A 30-day money-back guarantee for all new accounts is permitted on the sale of services under the following conditions:
-Refunds are only permitted before the service is started
-Refund must be requested 48 hours before the next billing date or service is set to take place
-Refunds are only permitted if service has not been met or modified to the client's written request
-Refunds are issued at the Operator's discretion and may be accepted or rejected.
Please direct refund requests to http://gp.marketing/refund. At any time during your contract term, you may upgrade or downgrade your service with Global Presence. In the event of a service downgrade, a prorated credit will be issued to your Global Presence account for the difference in the cost of the two services for the remainder of your original contract term. This credit will be applied to future months of service with Global Presence and cannot be refunded in cash. Downgrading your account may cause the loss of Content, features, or capacity of your account. We do not accept any liability for such loss. The client can downgrade and upgrade by choosing the service plan of their choice. When downgrading or upgrading, all set-up fees, and monthly maintenance fees apply.
25. Third-Party Services, Software, and Websites; No Implied Endorsement
Global Presence is not responsible for any loss or damage incurred as a result of your use of any third party’s service, product, software, or website, including but not limited to any content thereon such as text, documents, designs, images, clips, photographs, videos, artwork, graphics, audio, audio-visual files, messages, interactive and instant messaging, posts, functions, files, documents, or other materials (collectively, “Third Party Materials”) whether or not you were linked to or directed to any Third Party Materials by or through the Site or Service. Global Presence does not endorse or assume responsibility for any Third Party Materials. It makes no guarantee regarding the reliability, accuracy, nature, origin, quality, or use of third-party materials. You are solely responsible for ensuring that your use of any Third Party Materials, including those made available by or through the Site or Service, is done solely following all relevant laws and the terms and conditions of any applicable licenses or other agreement. In no event shall Global Presence be liable to you or any third party for your use or alleged use of any Third Party Materials.
Further, Third Party Materials, such as email, e-commerce, and payment services, including but not limited to, Authorize.net, PayPal, Square, and Stripe payment options, may be subject to the applicable third-party terms of service and privacy policies. You are solely responsible for reviewing, agreeing to, and complying with any such terms before you use any Third Party Materials. Your use of any Third Party Materials is at your own discretion and at risk. If you do not agree to the third party’s terms of service or license agreement, do not download or use the Third Party Materials. Your use of any Third Party Materials obtained through the Service does not transfer to you any rights, title, or interest in or to the Third Party Materials beyond the terms contained in the third party provider's terms of service or license. Any reference on the Site to any Third Party Materials is not an approval or endorsement by us of such Third Party Materials.
Third Party-Payment Processors: Global Presence uses third-party payment processors to assist us in securely processing your personally identifiable payment information. Such third-party processors’ use of your personal information is governed by their respective privacy policies, which may or may not contain privacy protections as protective as the Global Presence Privacy Notice. Payments are currently processed and managed using the third-party vendors below. We will inform you which payment processors are used when processing your payments.
Apple Pay and Android Pay are automatically activated for users who have selected Stripe as their payment processor. If you do not wish to accept Apple Pay or Android Pay as a payment type, you are responsible for deactivating Apple Pay and/or Android Pay. You can deactivate these payment options in your Store checkout settings. Your use of Apple Pay and Android Pay constitutes your acceptance of Apple Pay’s Acceptable Use Guidelines and/or Google/Android Pay’s (API) Terms of Service.
If you choose, you may contribute website themes ("Custom Themes") to the Service for use by other users. You hereby grant and agree to grant us an exclusive, perpetual, sublicensable, worldwide, irrevocable, royalty-free right and license to use, copy, modify, and create derivative works of any Custom Themes contributed by you to the Service, including the HTML code and associated media assets. The prices listed on our plans are for customizing our pre-designed templates. The plans allow the pricing of the design to be cost-effective. If the client seeks an original design, the cost will be $75 per hour for an average projected timeline of 20-60 hours.
27. Designer Platform Terms
If you use our Template Platform Service to design a website (a “Client Website”) for a third party (your “Client”), your use of the Service shall be subject to the additional terms outlined in this Section 16.
A. Your relationship with your Client is strictly between you and the Client. We will not be a party to any agreement you have with your Client. The manner and means that you choose to perform your services are in your sole discretion and control; however, you agree to perform these services in a timely and professional manner, consistent with industry practice and in conformance with these Terms.
B. You accept full responsibility for all Client Websites under your account and each Client Website’s adherence to these Terms.
C. While we intend to allow you to resell the service under a private label, this private label is in no way guaranteed. We will in no way be held responsible for any failure to maintain its private label.
D. If your Client contacts us, we will direct them to contact you. If you fail to support your Client, and we receive a request from your Client stating that you have not been responsive, we reserve the right to directly support your client.
E. Payments for your use of the Designer Platform Service are calculated on a per-website basis. Each Client Website under your account published live to a Client’s domain will incur monthly service charges. These service charges are billed to the credit card on file for your Global Presence account.
F. Service charges are billed each month for the upcoming month’s service, based on the total service charges of all Client Websites. If a new Client Website is published mid-month, a pro-rated amount will be included on your next month’s invoice.
G. No refunds will be given for any days remaining in your current billing cycle.
H. As the account owner, you understand and agree that you are ultimately responsible for payment for every Client Website under your account. If, at any time, the billing obligations of any Client Website are not met, we will have the right to disable the Client Website until the billing obligation is met.
28. Resale of Service
You will not reproduce, duplicate, copy, sell, resell, or exploit any portion of the Service without our express written permission, which may be in the form of a separate written agreement with Global Presence (such as the Global Presence Cloud Agreement).
Designers often use Global Presence to design websites for a third party. Such use is explicitly permitted under the Designer Platform terms above. Should you design websites for third parties on any version of Global Presence other than the Designer Platform, such sites must each have their own account controlled by the third party. You may not group multiple client sites under one account you own.
29. Domain Name Registration, Domain Name Cancellation, and Change of Registrar
For the domain name registration services (the “Domain Services”) provided to you by Global Presence, the following terms and conditions also apply (the “Domain Terms”). Your use of the Domain Services provided by Global Presence serves as your consent to these terms. Some service packages include Global Presence registering an Internet domain name or renewing your existing domain name (the “Domain Name”) on your behalf. To procure and/or maintain domains, Global Presence will act only as the agent between you and the domain name service provider responsible for domain name allocation (the “Registrar”), which will be Enom.com. Therefore, all new registrations and subsequent renewals of those registrations will therefore also be subject to the Enom.com terms and conditions located at https://www.enom.com/terms/privacy.aspx. Global Presence reserves the right to utilize another domain name service provider at any time, in which case the terms and conditions of such organization will apply complementarily to these Domain Terms, and such other domain name service provider shall be deemed a “Registrar” for purposes of these Terms.
Global Presence may provide one (1) free domain name for up to one year, with a new purchase of an annual or bi-annual subscription plan. The domain will be included for the lifetime of your Global Presence account. The domain will be registered in your name and is yours to keep, as long as you cover any applicable domain registration fees following the first year. When signing up for a new plan, the free domain name only applies to certain top-level domains (e.g., .com, .net, and .org).
You are responsible for providing correct and complete data regarding the domain name holder (“Registrant”) and the administrative contact when registering the domain name. The technical contact in all cases will be Global Presence, Inc. Before applying for a domain name, it is your responsibility to check that the domain name does not violate the rights of any third party or contravene any applicable law, rule, or regulation. We may defer activation of a domain name until payment of the agreed fees for the registration services has been received. Global Presence is in no position to influence the allocation of the domain name by the Registrar. We can neither guarantee that the requested domain names will be allocated to you and/or that allocated domain names are free of third-party rights nor guarantee their continued existence. Any information we provide regarding the availability of a domain name is based on the data provided by third parties and only refers to the time that information is requested. The domain will not be deemed as allocated before registration of the domain in the name of you, the Registrant, and its entry in the database of the Registrar.
The initial registration term for purchased domains may vary, and such registration will auto-renew for successive 12-month periods. You will be charged for auto-renewal forty-five (45) calendar days before your domain expires (even if that date differs from your Global Presence website subscription renewal date). You can, of course, opt out of auto-renewal by turning off the auto-renew option in your settings before the auto-renewal takes effect. Each purchased domain name is registered in your name and is yours to keep, as long as you pay the applicable fees. If you purchase a new domain or renew an existing domain and cancel your purchase within the first thirty (30) days by contacting https://gp.marketing, you may receive a full refund. Your right and title to your domain name allow you to transfer a purchased domain to another domain provider; however, you will not be eligible for a refund of registration fees paid to Global Presence for transferred domains. Regardless of the Registrant's identity or any other contact information in your domain name records, any domain name registered through your Global Presence account is covered by these Terms.
Maintaining accurate and current billing information is mandatory for maintaining your Global Presence account. Such data must include the full and real name of the Registrant, a physical mailing address (PO boxes or anonymous addresses are not permissible), a valid email address, and a telephone number. If this information changes, you must immediately inform us of this change by updating it online. Please note that if your billing information, including your current credit card information, is not current, we will not renew your Domain Services, and they may expire.
Subject to these Terms and those of the Registrar, you may transfer all domain names registered through us to another domain name service provider by following the online instructions provided by Global Presence. Should we, due to failure on the part of you, the account holder, or the new domain name service provider, be unable to make the domain transfer to your new domain name service provider, we are expressly entitled to have the canceled domain name deleted by the relevant domain name service provider after the cancellation date has lapsed. We will not be liable to you or any third party for such deletion. We reserve the right to allow domain transfers only if you have settled all undisputed pending claims with us.
It may not always be possible to recover a domain name after it has expired. Global Presence has sole discretion in determining when a domain name can be renewed post-expiry and what applicable fees. If you forfeit a domain name for non-payment, Global Presence will have the right, in its sole discretion, to (a) register and use the domain name for its purpose; (b) sell or transfer the domain name to a third party; or (c) delete the domain name and allow any new registrant anywhere in the world to register the domain name anew. Further, you agree that Global Presence may charge the credit card you have on file with Global Presence to recover any amounts outstanding on your account.
On certain occasions, domain name registrations may become the subject of a legal challenge. If Global Presence is made a party to any legal action by one of your domain name registrations, you agree to be responsible for all of Global Presence’s costs and legal fees and indemnify and hold Global Presence harmless from any action. If Global Presence is notified that a complaint has been filed with a judicial or administrative body regarding your domain name, Global Presence may, at its sole discretion: (a) lock or suspend your ability to use, make modifications to, or transfer your registration records; and/or (b) deposit control of your registration record with the appropriate judicial entity by supplying a registrar certificate from us.
You must notify us immediately if you lose the rights to a domain name registered by Global Presence on your behalf.
30. Email Marketing Service
The following terms and conditions also apply to the email marketing services provided directly to you by Global Presence (the “Email Marketing Service”). Your use of the Email Marketing Service serves as your consent to these terms. Global Presence may suspend or terminate your access to and use of the Email Marketing Service if you do not comply with these terms.
Your use of the Email Marketing Service must comply with all applicable domestic and international laws. This includes the laws applicable to you and to Global Presence and all recipients to whom you intend to send emails (each a “Recipient”). Examples of applicable laws include laws relating to spam or unsolicited commercial email (hereinafter “Spam” or “UCE”), privacy, security, obscenity, defamation, intellectual property, pornography, terrorism, homeland security, gambling, child protection, and other applicable laws. It is your responsibility to know and understand the laws applicable to your use of the Email Marketing Service and the emails you generate and send through the Email Marketing Service. Your use of the Email Marketing Service must also comply with the Privacy Notice applicable to the Email Marketing Service. Global Presence’s Privacy Notice is available here.
You are solely responsible for your products and services and any other promotion and content in or referred to in your emails sent through the Email Marketing Service. You agree to use the Email Marketing Service lawful, safe, and professional manner, consistent with industry best practices, including keeping reliable records. You are solely responsible for all statements you make, user assistance, warranty, and support of your products and services.
Your use of the Email Marketing Service must follow all applicable guidelines established by Global Presence. The guidelines below are examples of practices that may violate these Terms when generating or sending emails or messages through the Email Marketing Service:
You will not:
A. Use the Email Marketing Service in violation of Global Presence’s Terms of Service or any law applicable to you or your Recipients;
B. Use the Email Marketing Service to send Spam. You must ensure that all Recipients have explicitly granted permission to receive emails from you by affirmatively opting in to receive those emails. All emails and messages sent utilizing the Email Marketing Service must comply with our Anti-Spam Policy, as outlined below:
i. Global Presence has a no tolerance Spam policy and does not knowingly and intentionally do business with any user or company that participates in sending Spam/UCE. We do not sell or exchange personal information from our opt-in lists.
ii. An email is Spam if, among other things: (a) the Recipient’s identity and context are irrelevant because the message is equally applicable to many other potential recipients; (b) the Recipient has not verifiably granted deliberate, explicit, and still-revocable permission for it to be sent; and (c) the transmission and reception of the message appears to give a disproportionate benefit to the sender.
iii. Spam is an issue of consent, not content. A Recipient should “affirmatively opt-in” or expressly consent to receive the message, either in response to a clear and conspicuous request or at the recipient’s initiative.
The U.S. CAN-SPAM Act regulates and establishes requirements for commercial messages, gives recipients the right to have you stop emailing them, and spells out tough penalties for violations. Other international regulations and laws also apply to electronic marketing. While we cannot give legal advice, we encourage you to become familiar with these laws, especially if you live in or mail to recipients outside the U.S.
v. If you receive Spam complaints or run into compliance problems, or if Global Presence identifies a potentially problematic contact list, we will first ask questions to try to understand your business and marketing goals. If we determine that a list is not consent-based or too old or problematic to work with, we will require it to be removed from your account. We may ask you to find another service provider in certain instances because our goals are not compatible.
vi. Please refer to our Email Marketing FAQ in the Help Center for further guidance on becoming a responsible mailer and the ways that Global Presence helps protect against sending unwanted or unsolicited emails.
vii. If you feel a Global Presence user is sending an unsolicited email, you can report it to us by sending it to .
C. Use the Email Marketing Service to request, collect or send any non-public or personally identifiable information about another user or any other person without their express prior written consent (or the parent’s consent in the case of a minor), illegal information, or any other information you do not have the right to request, collect or distribute;
D. Use the Email Marketing Service to send email campaigns that link to or display pornography, other sexually explicit content, illegal goods or services, or any other Content that Global Presence deems inappropriate in its sole discretion;
E. Transmit any message, information, data, text, software or image, or other Content that is not owned by you or legally licensed to you, or is unlawful, harmful, threatening, abusive, harassing, defamatory, vulgar, obscene, libelous, or otherwise objectionable which may violate another’s right of privacy or publicity;
F. Send through the Email Marketing Service any unethical, false, or misleading advertising, promotions, or sales efforts and practices;
G. Post or transmit any materials that contain a virus or corrupted data;
H. Use purchased or rented email lists;
I. Use third party email addresses, domain names, or mail servers without proper permission;
K. Send emails that result in an unacceptable number of Spam or UCE complaints (even if the emails themselves were not Spam or UCE);
L. Disable or fail to include a working “unsubscribe” link in every email, which allows the Recipient/s to remove themselves from your mailing list. Each such link must remain operational for at least 60 days after the date on which you send the message, and you agree that you will not remove, disable or attempt to remove or disable the link;
M. Disable or fail to comply with any request from a Recipient to be removed from your mailing list within seven (7) calendar days of receipt of the request. You cannot charge a fee, require the recipient to give you any personally identifiable information beyond an email address or make the recipient take any step other than sending a reply email or visiting a single page on an Internet website as a condition for honoring an unsubscribe request. As required under the U.S. CAN-SPAM Act and other applicable laws, you acknowledge that you are responsible for maintaining and honoring the list of unsubscribe requests following termination of your Global Presence account, for any reason whatsoever;
N. Disguise any email's origin or subject matter or falsify or manipulate the originating email address, subject line, headers, or transmission path information for any email. For any email or message sent by you using the Email Marketing Service, (a) the “from” line must accurately and in a non-deceptive manner identify your identity or your organization’s identity; and (b) the “subject” line of your email must relate to the email’s actual content and must not contain any deceptive content regarding the overall subject matter of the email message. You agree that you are the sole or designated sender of any email you send through the Email Marketing Service, according to any law or act applicable to your use of the Email Marketing Service (e.g., U.S. CAN-SPAM Act of 2003, Canada’s Anti-Spam Legislation, S.C. 2010, c. 23 and Directive 2003/58/EC of the European Parliament and of the Council of 12 July 2002). As such, you must comply with such laws and any other laws in other jurisdictions that apply to your use of the Email Marketing Service and be responsible for any violation of any such applicable laws.
O. Fail to include in each email your valid physical mailing address (which, if you are located in the United States, maybe a valid post office box meeting the registration requirements established by the United States Postal Service) or a link to that information. For Recipients based in the EU, each email must additionally include the sender’s business registration number and VAT ID or a link to that information;
P. Include “junk mail,” “chain letters,” “pyramid schemes,” incentives (e.g., coupons, discounts, awards, or other incentives) or other material in any email that encourages a Recipient to forward the email to another recipient; or
Q. Fail to comply with export and import regulations for the U.S. and other countries.
Some industries yield higher than normal abuse rates for Spam. Thus, the Email Marketing Service may not be used on behalf of certain industries and senders. This includes, but is not limited to, the following:
i. Pharmaceutical products;
ii. Work from home, make money online, “get rich schemes”, and lead generation opportunities;
iii. Online trading, day trading tips, or stock market-related content;
iv. Mortgage and loan content;
v. Nutritional, herbal, and vitamin supplements;
vi. Gambling services, products, or tips;
vii. Multi-level marketing;
viii. Affiliate marketing or any type of performance marketing in which a business rewards or otherwise incentivize one or more affiliates for each visitor or customer brought by the affiliate’s marketing efforts;
ix. Credit repair and get out of debt opportunities; and
x. Counterfeit or “knock off” products appearing to be another brand.
Your responsibility is to ensure that the Content you put in your emails does not violate these guidelines. Although Global Presence has no obligation to do so, we may monitor your account to ensure compliance with these Terms and operations within the acceptable industry standards. In our sole discretion, we reserve the right to block emails, remove Content, or prohibit the use of the Email Marketing Service that may violate the foregoing or of the Terms (including SendGrid Terms). You understand and agree that we and any applicable third party that supports, posts, publishes, or distributes your emails. Content also has the right to reformat, edit, monitor, reject, block or remove any of your emails and content and suspend or terminate the Email Marketing Service, in whole or in part, permanently or temporarily. In no case will the foregoing make us responsible to you for compliance with any such laws or obligations, for which you remain solely responsible.
If you know of or suspect violations of these Terms, please notify Global Presence. Global Presence will determine compliance with these Terms in its sole discretion and reserves the right, without notice, to take all measures of any nature (legal, technical, or otherwise) or prevent UCE and/or any other unauthorized email, messages, or campaigns from entering, utilizing or remaining within our network. We may terminate the Email Marketing Service and your Global Presence account at any time and for any reason. We may permanently delete your account and any associated data if your account is terminated.
We will obtain any information that you provide us in connection with your use of the Email Marketing Service, such as contact lists (including email addresses and any other information contained in such lists) and Content posted or used by you for the Email Marketing Service, or in any other manner. We acknowledge your ownership rights in contact lists (“Customer Information”) and Content. We won’t sell or rent your Customer Information without your prior explicit permission or use your Customer Information for any purpose other than as described in our Privacy Notice and these Terms. SendGrid may also use the Customer Information and other information provided by you as part of the Email Marketing Service, following the SendGrid Terms.
You hereby grant us a revocable, non-exclusive, royalty-free, worldwide license, with the right to sublicense, use, reproduce, publish, distribute, perform and display Customer Information only as required by us to offer and operate the Email Marketing Service.
You are solely responsible for the accuracy, quality, integrity, legality, reliability, and appropriateness of all Customer Information. You are responsible for maintaining, securing, and storing all Customer Information by applicable law and your contractual obligations, including these Terms. You represent and warrant that you own or have rights in the material in your emails and the Customer Information required for us to use the Customer Information as contemplated by these Terms.
When using the Email Marketing Service, you agree that any emails, messages, and Content contained therein are non-confidential. You automatically grant or warrant that the owner of such Content or intellectual property has granted to us (or sub-licensed to us through you) a non-exclusive, royalty-free, perpetual, transferable, worldwide license, with the right to sublicense, to use, reproduce, create derivative works from, modify, publish, edit, translate, distribute, perform and display such Content or intellectual property in any manner or any media now known or hereafter created, including in connection with our marketing and promotional activities.
To the extent permitted by law, we may make and preserve copies of all Customer Information as necessary to provide the Email Marketing Service and for internal back-up and other legal or regulatory purposes. However, we are not obligated to preserve copies of your Customer Information, emails, messages, Content, or other data. You are responsible for backing up your Customer Information.
We make no representation or warranty that the content and materials on our website and/or the Email Marketing Service are appropriate for use in locations outside the United States. Those who access the Email Marketing Service from other locations do so at their own risk and are responsible for compliance with applicable local laws. At any time and at our sole discretion, we reserve the right to limit the availability, quantity, and accessibility of the Email Marketing Service to any person, geographic area, or jurisdiction.
You will indemnify, defend, and hold harmless Global Presence. Its subsidiaries, licensors, affiliates, officers, directors, agents, co-branders, partners, employees, successors, and assigns (collectively “Indemnified Parties”) from any liability, loss, claim, damages, expenses, costs, or demands (including but not limited to reasonable attorneys' fees), incurred or made against the Indemnified Parties by any third party in connection with any claim arising from or related to (a) your use (or anyone using your account/s) use of the Service, the Site or the Materials, (b) your Content, (c) any Commercial Products you offer on or through the Site or using our Services, or (d) your use of the Domain Services. This includes, but is not limited to, any breach or violation of these Terms by you or anyone utilizing your account. You must fully cooperate at your expense as required by an Indemnified Party. Each Indemnified Party may, at its election, assume the defense and control of any matter for which it is indemnified hereunder. You shall not settle any matter involving an Indemnified Party without the consent of the applicable Indemnified Party.
32. Disclaimer of warranties
A. YOUR USE OF THE SERVICE IS AT YOUR SOLE RISK. THE SERVICE IS PROVIDED ON AN "AS IS" AND "AS AVAILABLE" BASIS. WE EXPRESSLY DISCLAIM ALL WARRANTIES OF ANY KIND, WHETHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, AND NON-INFRINGEMENT.
B. WE ARE NOT RESPONSIBLE FOR ANY DAMAGE, LOSS OF DATA, CUSTOMER INFORMATION OR VENDOR DATA, REVENUE, OR OTHER HARM TO BUSINESS ARISING OUT OF DELAYS, MISDELIVERY OR NON-DELIVERY OF INFORMATION, RESTRICTION OR LOSS OF ACCESS, BUGS OR OTHER ERRORS, UNAUTHORIZED USE DUE TO YOUR SHARING OF ACCESS TO THE SERVICE, OR OTHER INTERACTION WITH THE SERVICE. YOU ARE RESPONSIBLE FOR MAINTAINING AND BACKING UP YOUR DATA AND INFORMATION THAT MAY RESIDE ON THE SERVICE. Global Presence DOES NOT WARRANT THAT (i) THE SERVICE WILL MEET YOUR SPECIFIC REQUIREMENTS, (ii) THE SERVICE WILL BE UNINTERRUPTED, TIMELY, SECURE, OR ERROR-FREE, (iii) THE RESULTS THAT MAY BE OBTAINED FROM THE USE OF THE SERVICE WILL BE ACCURATE OR RELIABLE, (iv) THE QUALITY OF ANY PRODUCTS, SERVICES, INFORMATION, OR OTHER MATERIAL PURCHASED OR OBTAINED BY YOU THROUGH THE SERVICE WILL MEET YOUR EXPECTATIONS, AND (V) ANY ERRORS IN THE SERVICE WILL BE CORRECTED.
C. ANY MATERIAL DOWNLOADED OR OTHERWISE OBTAINED THROUGH THE USE OF THE SERVICE IS DONE AT YOUR DISCRETION AND RISK, AND YOU WILL BE SOLELY RESPONSIBLE FOR ANY DAMAGE TO YOUR COMPUTER SYSTEM OR LOSS OF DATA THAT RESULTS FROM THE DOWNLOAD OF ANY SUCH MATERIAL.
D. ANY DATA, INFORMATION, CONTENT, OR MATERIALS CONTAINED IN OR MADE AVAILABLE IN CONNECTION WITH THE SERVICE ARE NOT INTENDED AS A SUBSTITUTE FOR THE KNOWLEDGE, EXPERTISE, SKILL, AND JUDGMENT OF TAX, LEGAL, OR OTHER PROFESSIONALS. THE SERVICE DOES NOT PROVIDE TAX OR LEGAL ADVICE. YOU ARE RESPONSIBLE FOR OBTAINING SUCH ADVICE, AND WE ENCOURAGE YOU TO DO SO BEFORE AND IN CONJUNCTION WITH USING OUR SERVICE.
E. THESE TERMS APPLY SOLELY TO THE SERVICE. AS PART OF THE SERVICES PROVIDED TO OTHER Global Presence USERS, WE HOST WEBSITES FOR CERTAIN THIRD PARTIES (“THIRD PARTY SITES”). THIRD-PARTY SITES INCLUDE CONTENT GENERATED BY THIRD PARTIES AND ARE NOT UNDER THE MANAGEMENT AND CONTROL OF Global Presence. Global Presence IS NOT RESPONSIBLE FOR SUCH THIRD PARTY SITES, INCLUDING, WITHOUT LIMITATION, THE ACCURACY, SUFFICIENCY, CORRECTNESS, RELIABILITY, VERACITY, COMPLETENESS OR TIMELINESS THEREOF, ANY LINK CONTAINED THEREIN, OR ANY CHANGES OR UPDATES THERETO, OR ANY GOODS OR SERVICES SOLD THEREON. YOUR ACCESS OR USE OF ANY THIRD-PARTY SITE IS GOVERNED BY THE TERMS APPLICABLE TO SUCH THIRD-PARTY SITE. THE HOSTING OF ANY THIRD PARTY SITE BY Global Presence DOES NOT IMPLY AN ENDORSEMENT THEREOF BY Global Presence, OR THE PROVIDER OF SUCH CONTENT OR SERVICES, OF ANY THIRD PARTY SITE.
F. NEITHER Global Presence NOR ANY THIRD PARTY PROVIDERS, PARTNERS, OR AFFILIATES WARRANT THE SITE, ITS SERVERS, THE MATERIALS OR THE SERVICE, OR ANY EMAIL SENT FROM THE SITE OR ANY THIRD PARTY PROVIDERS, PARTNERS, OR AFFILIATES ARE FREE OF VIRUSES OR OTHER HARMFUL COMPONENTS.
G. Global Presence AND ITS LICENSORS MAKE NO WARRANTY OR REPRESENTATION THAT THE SERVICES, MATERIALS, OR SITE ARE APPROPRIATE AVAILABLE FOR USE IN ALL GEOGRAPHIC LOCATIONS.
33 Limitation of Liability
TO THE EXTENT PERMITTED BY APPLICABLE LAW, WE WILL NOT BE LIABLE TO YOU OR ANY OTHER PERSON FOR ANY DIRECT, INDIRECT, INCIDENTAL, PUNITIVE, SPECIAL, CONSEQUENTIAL OR EXEMPLARY DAMAGES, INCLUDING BUT NOT LIMITED TO, DAMAGES FOR LOSS OF PROFITS, GOODWILL, USE, DATA OR OTHER INTANGIBLE LOSSES (EVEN IF Global Presence HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES), RESULTING FROM (a) THE USE OR THE INABILITY TO USE THE SERVICE; (b) THE COST OF PROCUREMENT OF SUBSTITUTE GOODS AND SERVICES RESULTING FROM ANY GOODS, DATA, INFORMATION OR SERVICES PURCHASED OR OBTAINED OR MESSAGES RECEIVED OR TRANSACTIONS ENTERED INTO THROUGH OR FROM THE SERVICE; (c) UNAUTHORIZED ACCESS TO OR ALTERATION OF YOUR TRANSMISSIONS OR DATA; (d) STATEMENTS OR CONDUCT OF ANY THIRD PARTY ON THE SERVICE; OR (e) ANY OTHER MATTER RELATING TO THE SERVICE.
IN THE EVENT OF ANY PROBLEM WITH THE SITE, THE SERVICE, OR THE MATERIALS, YOUR SOLE, EXCLUSIVE REMEDY, AS PERMITTED BY APPLICABLE LAW, IS TO CEASE USING THE SITE, THE SERVICE, AND THE MATERIALS. TO THE MAXIMUM EXTENT PERMISSIBLE BY APPLICABLE LAW, NEITHER Global Presence, ITS AFFILIATES, NOR LICENSORS SHALL BE LIABLE IN ANY WAY FOR YOUR USE OF THE SITE, THE SERVICE, THE MATERIALS, YOUR CONTENT, THE COMMERCIAL PRODUCTS, OR THIRD-PARTY USER GENERATED CONTENT AVAILABLE ON OR THROUGH THE SITE, INCLUDING, BUT NOT LIMITED TO, ANY ERRORS OR OMISSIONS, ANY INFRINGEMENT OF THE INTELLECTUAL PROPERTY RIGHTS OR OTHER RIGHTS OF THIRD PARTIES, OR FOR ANY LOSS OR DAMAGE OF ANY KIND INCURRED AS A RESULT OF, OR RELATED TO, THE USE OF THE SITE, THE SERVICE, THE MATERIALS, YOUR CONTENT, THE COMMERCIAL PRODUCTS OR ANY THIRD PARTY USER GENERATED CONTENT AVAILABLE ON OR THROUGH THE SITE.
34. Exclusions and Limitations
SOME JURISDICTIONS DO NOT ALLOW THE EXCLUSION OF CERTAIN WARRANTIES OR THE LIMITATION OR EXCLUSION OF LIABILITY FOR INCIDENTAL OR CONSEQUENTIAL DAMAGES AS OUTLINED IN SECTIONS 21 AND 22. ACCORDINGLY, SOME OF THE ABOVE LIMITATIONS OF SECTIONS 21 AND 22 MAY NOT APPLY TO YOU.
35. U.S. Government Restricted Rights
The materials on the Service are provided with "RESTRICTED RIGHTS." Use, duplication, or disclosure by the U.S. Government is subject to restrictions as outlined in applicable laws and regulations. Use of the materials by the U.S. Government constitutes acknowledgment of our proprietary rights in them.
36. Agreement to Arbitrate; Class Waiver
We want to address your concerns or issues before filing a claim against Global Presence. Please contact us at . We'll contact you by email to informally resolve the dispute. You or Global Presence may start a formal dispute resolution process if a dispute is not resolved within 30 days of your submission.
YOU MAY ONLY RESOLVE DISPUTES WITH US ON AN INDIVIDUAL BASIS, AND YOU WILL NOT BRING A CLAIM AS A PLAINTIFF OR A CLASS MEMBER IN A CLASS, CONSOLIDATED, OR REPRESENTATIVE ACTION (E.G., CLASS ACTION, CLASS ARBITRATION, PRIVATE ATTORNEY GENERAL ACTION, OR CONSOLIDATION WITH OTHER ARBITRATIONS).
Any claim relating to these Terms that is not resolved through our informal process, or as set forth below, will be resolved finally and exclusively by binding individual arbitration with a single arbitrator (the “Arbitrator”) administered by the American Arbitration Association (https://www.adr.org) according to this Section and the applicable arbitration rules for that forum. The Arbitrator shall be responsible for determining all threshold arbitrability issues, including whether the Terms are enforceable, unconscionable, or illusory, and any defense to arbitration, including waiver and delay, laches, or estoppel. Subject to applicable jurisdictional requirements, you may elect to pursue your claim in your local small-claims court rather than through arbitration so long as your matter remains in small claims court and proceeds only on an individual (non-class or non-representative) basis. The Federal Arbitration Act, 9 U.S.C. §§ 1-16, applies. If you are a consumer bringing a claim relating to a transaction intended for personal, household, or family use, any arbitration hearing will occur within the county where you reside. Otherwise, any arbitration hearing will occur in Broward, Florida, or another mutually agreeable location. The arbitrator’s award will be binding on the parties and may be entered as a judgment in any court of competent jurisdiction. While an arbitrator may award declaratory or injunctive relief, the Arbitrator may do so only concerning the individual party seeking relief and to the extent necessary to provide relief warranted by the individual party’s claim. An Arbitrator’s decision and judgment thereon will not have a precedential or collateral estoppel effect in any other case or arbitration. Global Presence will reimburse the arbitration fees due to the American Arbitration Association for individual arbitrations brought by this section for all claims totaling less than $10,000 unless the Arbitrator determines that your claims were frivolous. If you prevail on any claim, you are legally entitled to attorney’s fees; you may seek to recover those fees from the arbitrator. For any claim you seek relief, we will not seek to have you pay our attorney’s fees, even if fees might otherwise be awarded unless the Arbitrator determines that your claim was frivolous. For purposes of this arbitration provision, references to you and Global Presence also include respective subsidiaries, affiliates, agents, employees, predecessors, successors, assigns, and authorized users or beneficiaries of the Services. Subject to and without waiver of the arbitration provisions above, you agree that any judicial proceedings (other than small claims actions in consumer cases as discussed above) will be brought in. You hereby consent to the exclusive jurisdiction and venue in the state courts in the County of Broward, Florida, or federal court for the Southern District of Florida. If any part of these Terms is held invalid or unenforceable, that part will be construed to reflect the parties original intent, and the remaining portions will remain in full force and effect.
Either party may bring a lawsuit solely for injunctive relief to stop unauthorized use or abuse of the Service or to enforce intellectual property rights (e.g., copyright, trademark, trade secret, or patent rights) without engaging in our informal dispute resolution process or arbitration. If this agreement to arbitrate does not apply to you or your claim, any judicial proceeding will be brought to the federal or state courts of Broward County, Florida. You and Global Presence agree to submit to the personal and exclusive jurisdiction of the courts in Broward County, Florida. REGARDLESS OF ANY STATUTE OR LAW TO THE CONTRARY, ANY CLAIM OR CAUSE OF ACTION BROUGHT BY YOU ARISING OUT OF OR RELATED TO THE USE OF THE SERVICE OR THESE TERMS MUST BE FILED WITHIN ONE (1) YEAR AFTER SUCH CLAIM OR CAUSE OF ACTION AROSE OR BE FOREVER BARRED.
Please visit our Abuse page to report any violations of these Terms.
We may provide notices to you via either email or regular mail. The Service may also provide notices of changes to these Terms or other matters by displaying notices or links to notices to you generally on the Service. If your Country of Residence is the United States or Canada, these Terms and the relationship between you and Global Presence shall be governed by the laws of the State of Florida without regard to its conflict of law provisions. You and Global Presence agree to submit to the personal and exclusive jurisdiction of the courts in Broward, Florida.
These Terms constitute the entire agreement between you and us. They govern your use of the Service, superseding any prior agreements (including, but not limited to, any prior versions of these Terms). You may also be subject to additional terms and conditions when you use affiliate or other services, third-party content, or third-party software. If any provision of these Terms or incorporated documents are found by a court of competent jurisdiction to be invalid, the parties nevertheless agree that the court should endeavor to give effect to the party's intentions as reflected in the provision and the other provisions of these Terms remain in full force and effect. You agree that regardless of any statute or law to the contrary, any claim or cause of action brought by you arising out of or related to the use of the Service or these Terms must be filed within one (1) year after such claim or cause of action arose or be forever barred. The section titles in these Terms are for convenience only and have no legal or contractual effect. You acknowledge and agree that you are each waiving the right to participate as a plaintiff or class member in any purported class action or representative proceeding. Further, more than one person's claims may not be consolidated under any circumstances, in any form of any class or representative proceeding.
A person who is not a party to the agreement between us has no right to enforce any term of the engagement. The rights and remedies available to Global Presence under these Terms of Business are without prejudice to any other rights or remedies available to Global Presence. Any failure by Global Presence to exercise or delay in exercising a right or remedy provided by these Terms of Business or by law does not constitute a waiver of the right or remedy or a waiver of other rights or remedies.
The contract between us is based on these Terms of Business and is subject to US Law and the exclusive jurisdiction of the US Courts.
Global Presence looks forward to working with You. Your payment of an invoice will amount to an acceptance of these Standard Terms and Conditions.